Loading...
Hanna, McEldowney & Associates ~ C140029 City of Tigard III 13125 SW Hall Blvd. q CONTRACT CHANGE ORDER Tigard,Oregon 97223 f hone- (503) 639-4171 Phone#3 SUMMARY FORM 03 ax- X TIGARD Fax (� ) 684-7297 'x \vww.tigard-or.gov Project Title: Derry Dell Creek Culvert Replacement Project Manager: Kim McMillan Contractor: Hanna,McEldowney&Assoc. Original Contract#: C140029 Effective Dates: 8/8/13 Change Order/Amendment Amount: $ Accounting String: 510-8000-56005-93010-130 Amendment Percentage Running Total: 0% AMENDMENT DETAILS Change in termination date only. ICHANGE ORDER DETAILS UNIT QTY UNIT$ TOTAL$ I Original Contract $30,900.00 Amendment#1 $7,750.00 Amendment#2—date only 0 Amendment#3 —date only 0 TOTAL CONTRACT $38,650.00 REASONING FOR CHANGE ORDER/AMENDMENT It is important to keep the ROW agent under contract until the acquisition process is complete. REQUESTING PROJECT MANAGER APPROYIGITY STAFF Kim McMillan Signature Signature • -97 CIS" Date Date Contractor is hereby authorized by the City of Tigard to perform CONTRACTOR the additional work described below in accordance with the terms and conditions detailed in the original contract along with all applicable rules, regulations, and laws that may be in effect for Signature the work. The unit pricing in the original contract shall apply to all additional work. A copy of this form, once completed, is to be forwarded to the Purchasing Office to ensure all changes to the encumbrances are met. Remember—the cumulative total of Amendments cannot exceed the project's FY budget. Date tS CITY OF TIGARD,OREGON AMENDMENT TO CONTRACT DERRY DELL CREEK CULVERT REPLACEMENT- APPRAISAL AND ACQUISITION C140029 AMENDMENT #3 The Agreement between the City of Tigard, a municipal corporation of the State of Oregon, hereinafter called City, and Hanna McEldowney&Associates, hereinafter referred to as Contractor, entered into on the 8th day of August, 2013,is hereby amended as follows: 2. EFFECTIVE DATE AND DURATION This Agreement shall become effective upon the date of execution, and shall expire, unless otherwise terminated or extended,on Deeember-34r2014 June 30,2015. All work under this Agreement shall be completed prior to the expiration of this Agreement IN WITNESS WHEREOF, City has caused this Amendment to be executed by its duly authorized undersigned officer and Contractor has executed this Amendment upon signature and date listed below. CITY OF TIGARD HANNA MCELDOWNEY&ASSOCIATES Signature / Signatures Mat/fit/A& L (A)(1A e_, 0 H�� �.,. (CA �3 cL Printed Name Printed Naie Date Date City of Tigard III 13125 SW Hall Blvd. • CONTRACT CHANGE ORDER/ Tigard,Oregon 97223 AMENDMENT #2 SUMMARY FORM Phone- (503) 639-4171 T I G A R.D Fax- (503)684-7297 www.tigard-or.gov Project Title: Deny Dell Creek Culvert Replacement Project Manager: Kim McMillan Contractor: Hanna,McEldowney&Assoc. Original Contract#: C140029 Effective Dates: 8/8/13 Change Order/Amendment Amount: $ Accounting String: 510-8000-56005-93010-130 Amendment Percentage Running Total: 0% AMENDMENT DETAILS Hanna, McEldowney will obtain signatures on File #3 Ott and File #5 Cooley. Amendment 1 covered increase in scope of work.Amendment#2 is to extend the contract completion date through the process with the attorney ICHANGE ORDER DETAILS UNIT QTY UNIT$ TOTAL$ Original Contract $30,900.00 Amendment#1 $7,750.00 Amendment#2—date only 0 TOTAL CONTRACT $38,650.00 REASONING FOR CHANGE ORDER/AMENDMENT Multiple ROW files on the project have entered condemnation proceedings. It is important to keep the ROW agent under contract until the acquisition process is complete. REQUESTING PROJECT MANAGER APPRO CITY STAFF Kim McMillan ''1 .vlVAII 7 Signature Signature Ti 2-4D 14' Date / Date Contractor is hereby authorized by the City of Tigard to perform CONTRACTOR the additional work described below in accordance with the terms and conditions detailed in the original contract along with all applicable rules, regulations, and laws that may be in effect for Signature the work. The unit pricing in the original contract shall apply to all additional work. A copy of this form, once completed, is to be forwarded to the Purchasing Office to ensure all changes to the encumbrances are met. Remember—the cumulative total Date of Amendments cannot exceed the project's FY budget. CITY OF TIGARD, OREGON AMENDMENT TO PERSONAL SERVICES CONTRACT DERRY DELL CREEK CULVERT REPLACEMENT- APPRAISAL AND ACQUISITION CONTRACT#C140029 AMENDMENT #2 THIS CONTRACT,made and entered into this 8th day of August,2013,by and between the City of Tigard, a municipal corporation of the State of Oregon,hereinafter called City,and Hanna McEldowney& Associates,hereinafter called Consultant. 2. Effective Date and Duration This Agreement shall become effective upon the date of execution and shall expire,unless otherwise terminated or extended, upon completion of the work or June 30, 2014 December 31, 2014. All work under this Agreement shall be completed prior to the expiration of this Agreement. IN WITNESS WHEREOF, City has caused this amendment to be executed by its duly authorized undersigned officer and Contractor has executed this Amendment upon signature and date listed below. CITY OF TIGARD HA MCELDOWNEY&ASSOCIATES Signature Signature M v Wv�� e H . Printed Name Printed Na e 7" Z ` �`� t 3O) x.01 Date Date City of Tigard 13125 SW Hall Blvd. CONTRACT CHANGE ORDER Tigard,Oregon 97223 AMENDMENT #1 SUMMARY FORM Phone- (503) 639-4171 TIGARD Fax- (503) 684-7297 www.tigard-or.gov Project Title: Derry Dell Creek Culvert Replacement Project Manager: Kim McMillan Contractor: Hanna, McEldowney&Assoc. Original Contract #: C140029 Effective Dates: 8/8/13 Change Order/Amendment Amount: $7,750.00 Accounting String: 510-8000-56005-93010-130 Amendment Percentage Running Total: 25% AMENDMENT DETAILS Two files, File #1 Haddock and File #2 Shelledy will require that the city get a partial release of mortgage, Hanna, McEldowney will work with the City and the lender on these properties. Hanna, McEldowney will obtain signatures on File #3 Ott and File #5 Cooley. Additional amount required for work outside the scope of typical negotiations. CHANGE ORDER DETAILS UNIT QTY UNIT$ TOTAL$ $7,750.00 REASONING FOR CHANGE ORDER/AMENDMENT Multiple ROW files on the project have entered condemnation proceedings requiring additional time for the ROW agent. REQUESTING PROJECT MANAGER PR AP G CITY STAFF Kim McMillan Signature Siimature '6/ 422, Date � Date Contractor is hereby authorized by the City of Tigard to perform CONTRACTOR the additional work described below in accordance with the terms and conditions detailed in the original contract along with all ' applicable rules, regulations, and laws that may be in effect for Signature the work. The unit pricing in the original contract shall apply to all additional work. A copy of this form, once completed, is to be forwarded to the Purchasing Office to ensure all changes to the encumbrances are met. Remember—the cumulative total Date of Amendments cannot exceed the project's FY budget. CITY OF TIGARD,OREGON AMENDMENT TO PERSONAL SERVICES CONTRACT DERRY DELL CREEK CULVERT REPLACEMENT- APPRAISAL AND ACQUISITION AMENDMENT #1 THIS CONTRACT, made and entered into on the 8th day of August,2013,by and between the City of Tigard,a municipal corporation of the State of Oregon, hereinafter called City, and Hanna McEldowney& Associates, hereinafter called Consultant,is hereby amended as follows. 3. Compensation The City agrees to pay Consultant in accordance with the fee schedule outlined in Exhibit A for performance of those services described herein and in any subsequent agreements that arise from the work under this Agreement. The total amount paid to the Consultant by the City shall not exceed Thir y-Thousa -and-No/-100 Dehaas--($30,900:00)Thirty-Eight Thousand Six Hundred Fifty and No/100 Dollars ($38,650.00) if all tasks are completed. Any and all payments made to the Consultant shall be based upon the following applicable terms: IN WITNESS WHEREOF, City has caused this Amendment to be executed by its duly authorized undersigned officer and Contractor has executed this Amendment upon signature and date listed below. CITY OF TIGARD HANNA MCELDOWNEY&ASSOCIATES P' L410 Signature Signature Printed Name Printed Name j . 2-o cq, �:., . Q i q Date Date HA VNA,MCELDOWNEY&ASSOCIATES 8835 S.W. Cornrow LANE,Sur'rE 405 PoRTLA D,OR 97225 {503) 297-9588 Fax: (503) 297-2835 MEMO DATE: April 30,2014 TO: Laura Bathe FROM: Roger Hanna RE: Deny Dell Project-Additional Work Scope of Work 1) HMA will assist Chicago Title Company in securing a "partial release" from the mortgage for both File#1 (Haddock) and.File#2 (Shelledy). This assistance will consist of communicating with the City and escrow and providing the lender with written responses to their request for information concerning the partial taking and impact to the remainder. 2) If requested by the City,HMA will meet with the owners of File#3 (Ott) and File#5(Cooley)to secure their signature on legal documents after a negotiated agreement is reached by the attorney. 3) HMA will respond to the City and/or attorney regarding questions and/or documents for file#4 (Gonzalez). Following is a projected budget for this scope of work including the overage cost for Invoice#6. This budget does not include any cost for expert witness fees for pre-trial research or condemnation trial testimony. File#1: $1,550 File#2: $1,550 File#3: $500 File#4: $150 File#5: $500 Invoice#6: $3,500 $7,750 CITY OF TIGARD,OREGON CONTRACT SUMMARY FORM (FORM MUST ACCOMPANY EACH CONTRACT FOR AUTHORIZATION) Contract Title: Derry Dell Creek Culvert Replacement Number: C J (a. Contractor: Hanna,McEldowney&Associates Contract Total: $30,900 Contract Overview: Appraisal and Acqusition of Easements and Rights of Way . Type: ❑ Purchase Agreement Start Date: July 23, 2013 End Date: June 30,2014 X Personal Service ❑ Public Improvement LCRB Award: Department: PW/Engineering ❑ IGA ❑ Other: Contract Manager: Kim McMillan Quotes/Bids/Proposal: FIRM AMOUNT/SCORE Hanna, McEldowney&Associates $30,900 Right of Way Associates $32,600 Epic Land Solutions $58,745 Account String: Fund-Division-Account Project-Fund-Phase Amou t 52% 510-8000-56005 94011-100 $16,068 11% 532-8000-56005 96032-100 $3399 37% 500-8000-56005 93010-100 $11,433 Approvals Department Comments: .Hanna McEldowney&Associates was found to be the low responsive bidder Department Signature: 401()----Y0,;(atti Purchasing Comments: 1 Purchasing Signatur e City Manager Comments. /2/4City Manager Signature: After securing all required approvals,forward original copy to the Contracting and Purchasing Office along with a completed Contract Checklist. I:•\ENG11 - Active Projects194011 Derry Dell Culvert Rep at Walnut Street\Agreements-Contracts-IGA\Contract Summary_Hanna,Mc 2013.docx Contract Number C (MO A -9 CITY OF TIGARD,OREGON PERSONAL SERVICES CONTRACT DERRY DELL CREEK CULVERT REPLACEMENT- APPRAISAL AND ACQUISITION THIS AGREEMENT made and entered into this 8th day of August,2013 by and between the City of Tigard, a municipal corporation of the State of Oregon,hereinafter called City, and Hanna McEldowney&Associates, hereinafter called Consultant. RECITALS WHEREAS, the City's 2013-2014 fiscal year budget provides for services related to property acquisition for the Derry Dell Creek Culvert Replacement and Sanitary Sewer(CIP#93010);and WHEREAS, City has need for the services of a company with a particular training, ability, knowledge, and experience possessed by Consultant,and WHEREAS, City has determined that Consultant is qualified and capable of performing the professional services as City does hereinafter require,under those terms and conditions set forth, THEREFORE,the Parties agree as follows: 1. SERVICES TO BE PROVIDED Consultant shall initiate services immediately upon receipt of City's notice to proceed together with an executed copy of this Agreement. Consultant agrees to complete work that is detailed in Exhibit A and by this reference made a part hereof. Any and all work assigned by the City will be contained in subsequent scope of work as needed 2. EFFECTIVE DATE AND DURATION This Agreement shall become effective upon the date of execution, and shall expire, unless otherwise terminated or extended, on June 30, 2014. All work under this Agreement shall be completed prior to the expiration of this Agreement. 3. COMPENSATION The City agrees to pay Consultant in accordance with the fee schedule outlined in Exhibit A for performance of those services described herein and in any subsequent agreements that arise from the work under this Agreement. The total amount paid to the Consultant by the City shall not exceed Thirty Thousand Nine Hundred and No/100 Dollars ($30,900.00) if all tasks are completed. Any and all payments made to the Consultant shall be based upon the following applicable terms: A. Payment by City to Consultant for performance of services under this Agreement includes all expenses incurred by Consultant, with the exception of expenses, if any identified in this Agreement as separately reimbursable. B. Payment will be made in installments based on Consultant's invoice, subject to the approval of the City Manager, or designee, and not more frequently than monthly. Payment shall be made only for work actually completed as of the date of invoice. C. Payment by City shall release City from any further obligation for payment to Consultant, for services performed or expenses incurred as of the date of the invoice. Payment shall not be considered acceptance or approval of any work or waiver of any defects therein. D. Consultant shall make payments promptly, as due, to all persons supplying labor or materials for the prosecution of this work. E. Consultant shall not permit any lien or claim to be filed or prosecuted against the City on any account of any labor or material furnished. F. Consultant shall pay to the Department of Revenue all sums withheld from employees pursuant to ORS 316.167. G. If Consultant fails, neglects or refuses to make prompt payment of any claim for labor or services furnished to Consultant or a subcontractor by any person as such claim becomes due, City's Finance Director may pay such claim and charge the amount of the payment against funds due or to become due the Consultant. The payment of the claim in this manner shall not relieve Consultant or their surety from obligation with respect to any unpaid claims. H. Consultant shall pay employees at least time and a half pay for all overtime worked in excess of 40 hours in any one week except for individuals under the contract who are excluded under ORS 653.010 to 653.261 or under 29 USC sections 201 to 209 from receiving overtime. I. Consultant shall promptly, as due,make payment to any person, co-partnership, association or corporation, furnishing medical, surgical and hospital care or other needed care and attention incident to sickness or injury to the employees of Consultant or all sums which Consultant agrees to pay for such services and all moneys and sums which Consultant collected or deducted from the wages of employees pursuant to any law, contract or agreement for the purpose of providing or paying for such service. J. The City certifies that sufficient funds are available and authorized for expenditure to finance costs of this contract during the current fiscal year. Funding during future fiscal years shall be subject to budget approval by Tigard's City Council. 4. OWNERSHIP OF WORK PRODUCT City shall be the owner of and shall be entitled to possession of any and all work products of Consultant which result from this Agreement,including any computations,plans, correspondence or pertinent data and information gathered by or computed by Consultant prior to termination of this Agreement by Consultant or upon completion of the work pursuant to this Agreement. 5. ASSIGNMENT/DELEGATION Neither party shall assign, sublet or transfer any interest in or duty under this Agreement without the written consent of the other and no assignment shall be of any force or effect whatsoever unless and until the other party has so consented. If City agrees to assignment of tasks to a subcontract, Consultant shall be fully responsible for the acts or omissions of any subcontractors and of all persons employed by them, and neither the approval by City of any subcontractor nor anything contained herein shall be deemed to create any contractual relation between the subcontractor and City. 2 1 P a g e 6. STATUS OF CONSULTANT AS INDEPENDENT CONSULTANT Consultant certifies that: A. Consultant acknowledges that for all purposes related to this Agreement,Consultant is and shall be deemed to be an independent Consultant as defined by ORS 670.600 and not an employee of City,shall not be entitled to benefits of any kind to which an employee of City is entitled and shall be solely responsible for all payments and taxes required by law. Furthermore,in the event that Consultant is found by a court of law or any administrative agency to be an employee of City for any purpose, City shall be entitled to offset compensation due, or to demand repayment of any amounts paid to Consultant under the terms of this Agreement, to the full extent of any benefits or other remuneration Consultant receives (from City or third party) as a result of said finding and to the full extent of any payments that City is required to make (to Consultant or to a third party) as a result of said finding. B. The undersigned Consultant hereby represents that no employee of the City,or any partnership or corporation in which a City employee has an interest,has or will receive any remuneration of any description from Consultant, either directly or indirectly, in connection with the letting or performance of this Agreement,except as specifically declared in writing. If this payment is to be charged against Federal funds, Consultant certifies that he/she is not currently employed by the Federal Government and the amount charged does not exceed his or her normal charge for the type of service provided. Consultant and its employees,if any, are not active members of the Oregon Public Employees Retirement System and are not employed for a total of 600 hours or more in the calendar year by any public employer participating in the Retirement System. C. Consultant certifies that it currently has a City business license or will obtain one prior to delivering services under this Agreement. D. Consultant is not an officer, employee, or agent of the City as those terms are used in ORS 30.265. 7. INDEMNIFICATION City has relied upon the professional ability and training of Consultant as a material inducement to enter into this Agreement. Consultant warrants that all its work will be performed in accordance with generally accepted professional practices and standards as well as the requirements of applicable federal, state and local laws, it being understood that acceptance of a Consultant's work by City shall not operate as a waiver or release. Consultant agrees to indemnify and defend the City,its officers, agents and employees and hold them harmless from any and all liability,causes of action,claims,losses,damages,judgments or other costs or expenses including attorney's fees and witness costs and(at both trial and appeal level,whether or not a trial or appeal ever takes place) that may be asserted by any person or entity which in any way arise from, during or in connection with the performance of the work described in this contract, except liability arising out of the sole negligence of the City and its employees. Such indemnification shall also cover claims brought against the City under state or federal worker's compensation laws. If any aspect 3 I Page of this indemnity shall be found to be illegal or invalid for any reason whatsoever, such illegality or invalidity shall not affect the validity of the remainder of this indemnification. 8. INSURANCE Consultant and its subcontractors shall maintain insurance acceptable to City in full force and effect throughout the term of this contract. Such insurance shall cover all risks arising directly or indirectly out of Consultant's activities or work hereunder,including the operations of its subcontractors of any tier. The policy or policies of insurance maintained by the Consultant and its subcontractor shall provide at least the following limits and coverages: A. Commercial General Liability Insurance Consultant shall obtain, at Consultant's expense, and keep in effect during the term of this contract, Comprehensive General Liability Insurance covering Bodily Injury and Property Damage on an "occurrence" form (1996 ISO or equivalent). This coverage shall include Contractual Liability insurance for the indemnity provided under this contract. The following insurance will be carried: Coverage Limit General Aggregate 2,000,000 Products-Completed Operations Aggregate 1,000,000 Personal&Advertising Injury 1,000,000 Each Occurrence 1,000,000 Fire Damage (Any one fire) 50,000 Medical Expense (Any one person) 5,000 B. Commercial Automobile Insurance Consultant shall also obtain, at Consultant's expense, and keep in effect during the term of the contract, Commercial Automobile liability coverage including coverage for all owned, hired, and non-owned vehicles. The Combined Single Limit per occurrence shall not be less than$z,000,O0 '" i)00o)00©, 'N,A4 C. Workers'Compensation Insurance The Consultant,its Subcontractors,if any,and all employers providing work,labor,or materials under this Contract that are subject employers under the Oregon Workers' Compensation Law shall comply with ORS 656.017, which requires them to provide workers' compensation coverage that satisfies Oregon law for all their subject workers. Out-of-state employers must provide Oregon workers' compensation coverage for their workers who work at a single location within Oregon for more than 30 days in a calendar year. Consultants who perform work without the assistance or labor of any employee need not obtain workers' compensation coverage. All non-exempt employers shall provide Employer's Liability Insurance with coverage limits of not less than$500,000 each accident. 4 IPagc D. Additional Insured Provision The Commercial General Liability Insurance and Commercial Automobile Insurance policies and other policies the City deems necessary shall include the City,its officers, directors, and employees as additional insureds with respect to this contract. E. Insurance Carrier Rating Coverages provided by the Consultant must be underwritten by an insurance company deemed acceptable by the City. The City reserves the right to reject all or any insurance carrier(s)with an unacceptable financial rating. F. Certificates of Insurance As evidence of the insurance coverage required by the contract, the Consultant shall furnish a Certificate of Insurance to the City. No contract shall be effected until the required certificates have been received and approved by the City. The certificate will specify and document all provisions within this contract. A renewal certificate will be sent to the above address 10 days prior to coverage expiration. G. Independent Consultant Status The service or services to be rendered under this contract are those of an independent Consultant. Consultant is not an officer, employee or agent of the City as those terms are used in ORS 30.265. H. Primary Coverage Clarification The parties agree that Consultant's coverage shall be primary to the extent permitted by law. The parties further agree that other insurance maintained by the City is excess and not contributory insurance with the insurance required in this section. I. Cross-Liability Clause A cross-liability clause or separation of insureds clause will be included in all general liability, professional liability,pollution and errors and omissions policies required by this contract. A copy of each insurance policy, certified as a true copy by an authorized representative of the issuing insurance company, or at the discretion of City,in lieu thereof, a certificate in form satisfactory to City certifying to the issuance of such insurance shall be forwarded to: City of Tigard Attn: Office of Risk Management 13125 SW Hall Blvd. Tigard,Oregon 97223 Such policies or certificates must be delivered prior to commencement of the work. The procuring of such required insurance shall not be construed to limit Consultant's liability hereunder. Notwithstanding said insurance, Consultant shall be obligated for the total amount of any damage, injury,or loss caused by negligence or neglect connected with this contract. 51Page 9. METHOD &PLACE OF SUBMITTING NOTICE,BILLS AND PAYMENTS All notices, bills and payments shall be made in writing and may be given by personal delivery,mail or by fax. Payments may be made by personal delivery, mail, or electronic transfer. The following addresses shall be used to transmit notices,bills,payments,and other information: ittirslori6 CIO Dun Attn: Kim McMillan,Engineering Manager Attn: Roger Hanna Address: 13125 SW Hall Blvd. Address: 8835 SW Canyon Lane,Suite 405 Tigard OR 97223 Portland OR 97225 Phone: (503) 718-2642 Phone: (503) 297-9588 Fax: (503) 624-0752 Fax: (503) 297-2835 Email: kim @tigard-or.gov Email: rogerhanna ct,gwestoffice.net and when so addressed, shall be deemed given upon deposit in the United States mail,postage prepaid, or when so faxed, shall be deemed given upon successful fax. In all other instances, notices, bills and payments shall be deemed given at the time of actual delivery. Changes may be made in the names and addresses of the person to who notices,bills and payments are to be given by giving written notice pursuant to this paragraph. 10. MERGER This writing is intended both as a final expression of the Agreement between the parties with respect to the included terms and as a complete and exclusive statement of the terms of the Agreement. No modification of this Agreement shall be effective unless and until it is made in writing and signed by both parties. 11. PROFESSIONAL SERVICES The City requires that services provided pursuant to this agreement shall be provided to the City by a Consultant that does not represent clients on matters contrary to City interests. Further, Consultant shall not engage services of an attorney and/or other professional who individually, or through members of his/her same firm,represents clients on matters contrary to City interests. Should the Consultant represent clients on matters contrary to City interests or engage the services on an attorney and/or other professional who individually, or through members of his/her same firm, represents clients on matters contrary to City interests, Consultant shall consult with the appropriate City representative regarding the conflict. After such consultation, the Consultant shall have seven (7) days to eliminate the conflict to the satisfaction of the City. If such conflict is not eliminated within the specified time period, the agreement may be terminated pursuant to Section 13 (B) (3) of this agreement. 12. TERMINATION WITHOUT CAUSE At any time and without cause, City shall have the right in its sole discretion, to terminate this Agreement by giving notice to Consultant. If City terminates the contract pursuant to this paragraph,it shall pay Consultant for services rendered to the date of termination. Wage 13. TERMINATION WITH CAUSE A. City may terminate this Agreement effective upon delivery of written notice to Consultant,or at such later date as may be established by City,under any of the following conditions: 1) If City funding from federal,state,local,or other sources is not obtained and continued at levels sufficient to allow for the purchase of the indicated quantity of services. This Agreement may be modified to accommodate a reduction in funds 2) If federal or state regulations or guidelines are modified,changed,or interpreted in such a way that the services are no longer allowable or appropriate for purchase under this Agreement. 3) If any license or certificate required by law or regulation to be held by Consultant, its subcontractors, agents, and employees to provide the services required by this Agreement is for any reason denied,revoked,or not renewed. 4) If Consultant becomes insolvent, if voluntary or involuntary petition in bankruptcy is filed by or against Consultant,if a receiver or trustee is appointed for Consultant, or if there is an assignment for the benefit of creditors of Consultant. Any such termination of this agreement under paragraph (a) shall be without prejudice to any obligations or liabilities of either party already accrued prior to such termination. B. City, by written notice of default (including breach of contract) to Consultant, may terminate the whole or any part of this Agreement: 1) If Consultant fails to provide services called for by this agreement within the time specified herein or any extension thereof;or 2) If Consultant fails to perform any of the other provisions of this Agreement, or so fails to pursue the work as to endanger performance of this agreement in accordance with its terms, and after receipt of written notice from City, fails to correct such failures within ten (10) days or such other period as City may authorize. 3) If Consultant fails to eliminate a conflict as described in Section 11 of this agreement. The rights and remedies of City provided in the above clause related to defaults (including breach of contract) by Consultant shall not be exclusive and are in addition to any other rights and remedies provided by law or under this Agreement. If City terminates this Agreement under paragraph (b),Consultant shall be entitled to receive as full payment for all services satisfactorily rendered and expenses incurred, an amount which bears the same ratio to the total fees specified in this Agreement as the services satisfactorily rendered by Consultant bear to the total services otherwise required to be performed for such total fee; provided, that there shall be deducted from such amount the amount of damages, if any,sustained by City due to breach of contract by Consultant. Damages for breach of contract shall be those allowed by Oregon law, reasonable and necessary attorney fees, and other costs of litigation at trial and upon appeal. 7IPage 14. ACCESS TO RECORDS City shall have access to such books, documents, papers and records of Consultant as are directly pertinent to this Agreement for the purpose of making audit,examination, excerpts and transcripts. 15. FORCE MAJEURE Neither City nor Consultant shall be considered in default because of any delays in completion and responsibilities hereunder due to causes beyond the control and without fault or negligence on the part of the parties so disenabled, including but not restricted to, an act of God or of a public enemy, civil unrest, volcano, earthquake, fire, flood, epidemic, quarantine restriction, area-wide strike, freight embargo, unusually severe weather or delay of subcontractor or supplies due to such cause; provided that the parties so disenabled shall within ten (10) days from the beginning of such delay, notify the other party in writing of the cause of delay and its probable extent. Such notification shall not be the basis for a claim for additional compensation. Each party shall,however,make all reasonable efforts to remove or eliminate such a cause of delay or default and shall, upon cessation of the cause, diligently pursue performance of its obligation under the Agreement. 16. NON-WAIVER The failure of City to insist upon or enforce strict performance by Consultant of any of the terms of this Agreement or to exercise any rights hereunder should not be construed as a waiver or relinquishment to any extent of its rights to assert or rely upon such terms or rights on any future occasion. 17. NON-DISCRIMINATION Consultant agrees to comply with all applicable requirements of federal and state civil rights and rehabilitation statutes, rules, and regulations. Consultant also shall comply with the Americans with Disabilities Act of 1990, ORS 659A.142, and all regulations and administrative rules established pursuant to those laws. 18. ERRORS Consultant shall perform such additional work as may be necessary to correct errors in the work required under this Agreement without undue delays and without additional cost. 19. EXTRA(CHANGES)WORK Only the City's Project Manager for this Agreement may authorize extra(and/or change)work. Failure of Consultant to secure authorization for extra work shall constitute a waiver of all right to adjustment in the contract price or contract time due to such unauthorized extra work and Consultant thereafter shall be entitled to no compensation whatsoever for the performance of such work. 20. WARRANTIES All work shall be guaranteed by Consultant for a period of one year after the date of final acceptance of the work by the owner. Consultant warrants that all practices and procedures, workmanship and materials shall be the best available unless otherwise specified in the profession. Neither acceptance of the work nor payment therefore shall relieve Consultant from liability under warranties contained in or implied by this Agreement. 81Page 21. ATTORNEY'S FEES In case suit or action is instituted to enforce the provisions of this contract, the parties agree that the losing party shall pay such sum as the court may adjudge reasonable attorney fees and court costs, including attorney's fees and court costs on appeal. 22. GOVERNING LAW The provisions of this Agreement shall be construed in accordance with the provisions of the laws of the State of Oregon. Any action or suits involving any question arising under this Agreement must be brought in the appropriate court of the State of Oregon. 23. COMPLIANCE WITH STATE AND FEDERAL LAWS/RULES Consultant shall comply with all applicable federal, state and local laws, rules and regulations, including, but not limited to, the requirements concerning working hours, overtime, medical care, workers compensation insurance, health care payments, payments to employees and subcontractors and income tax withholding contained in ORS Chapters 279A, 279B and 279C, the provisions of which are hereby made a part of this agreement. 24. CONFLICT BETWEEN TERMS It is further expressly agreed by and between the parties hereto that should there be any conflict between the terms of this instrument in the proposal of the contract, this instrument shall control and nothing herein shall be considered as an acceptance of the said terms of said proposal conflicting herewith. 25. AUDIT Consultant shall maintain records to assure conformance with the terms and conditions of this Agreement,and to assure adequate performance and accurate expenditures within the contract period. Consultant agrees to permit City, the State of Oregon,the federal government,or their duly authorized representatives to audit all records pertaining to this Agreement to assure the accurate expenditure of funds. 26. SEVERABILITY In the event any provision or portion of this Agreement is held to be unenforceable or invalid by any court of competent jurisdiction,the validity of the remaining terms and provisions shall not be affected to the extent that it did not materially affect the intent of the parties when they entered into the agreement. 27. CONDITIONS OF SUPPLYING A PUBLIC AGENCY Where applicable, seller must make payment promptly as due to persons supplying Consultant labor or materials for the execution of the work provided by this order. Consultant must pay all contributions or amounts due from Consultant to the Industrial Accident Fund incurred in the performance of this order. Consultant shall not permit any lien or claim to be filed or prosecuted against Buyer or any subdivision of City on account of any labor or material to be furnished. Consultant further agrees to pay to the Department of Revenue all sums withheld from employees pursuant to ORS 316.167. 9IPage: 28. HOURS OF LABOR If labor is performed under this order,then no person shall be employed for more than eight(8) hours in any one day, or forty (40) hours in any one week, except in cases of necessity, or emergency or where the public policy absolutely requires it, and in such cases, except cases of contracts for personal services as defined in ORS 279A.055,the labor shall be paid at least time and a half for all overtime in excess of eight (8) hours a day and for all work performed on Saturday and on any legal holidays as specified in ORS 279C.540. In cases of contracts for personal services as defined in ORS 279A.055,any labor shall be paid at least time and a half for all hours worked in excess of forty(40) hours in any one week,except for those individuals excluded under ORS 653.010 to 653.260 or under 29 USC SS 201-209. 29. MEDICAL CARE AND WORKERS'COMPENSATION Consultant shall promptly,as due,make payment to any person,co-partnership,association or corporation, furnishing medical, surgical and hospital care or other needed care and attention incident to sickness or injury, to the employees of such Consultant, of all sums which the Consultant agrees to pay for such services and all moneys and sums which the Consultant collected or deducted from the wages of the employees pursuant to any law, Consultant agreement for the purpose of providing or paying for such service. 30. COMPLETE AGREEMENT This Agreement and attached exhibits constitutes the entire Agreement between the parties. No waiver, consent, modification, or change of terms of this Agreement shall bind either party unless in writing and signed by both parties. Such waiver, consent, modification, or change if made, shall be effective only in specific instances and for the specific purpose given. There are no understandings, agreements, or representations, oral or written, not specified herein regarding this Agreement. Consultant, by the signature of its authorized representative, hereby acknowledges that he has read this Agreement,understands it and agrees to be bound by its terms and conditions. IN WITNESS WHEREOF, City has caused this Agreement to be executed by its duly authorized undersigned officer and Consultant has executed this Agreement on the date hereinabove first written. CITY OF TIGARD HANNA MCELDOWNEY&ASSOCIATES By: By:Autho ed Agent of Consultant Date Date 10 Page EXHIBIT A SERVICES To BE PROVIDED PROJECT Appraisal and acquisition of right of way and easements for the Deny Dell Culvert Replacement Project. Consultant shall follow Federal and State appraisal,acquisition, and relocation procedures as required by the Uniform Act and ODOT Right of Way Manual. Appraisals Consultant shall provide Taking and Damage appraisal reports for City review and setting of Just Compensation for each of five properties. Fee: $14,900 Appraisal Reviews Consultant shall provide the City with an appraisal review by a qualified appraiser for each of the five properties. Fee: $ 3,250 Acquisitions Consultant shall negotiate agreements with each of the five property owners and provide the City with an on-going detailed status report and a final settlement packet (including signed legal documents, diary of owner contacts, and other required documents and communications). If it is necessary for the City to file condemnation, we will provide a Recommendation for Condemnation along with the necessary file documents to the City and/or attorney. Fee: $12,750 (Fee does not include trial preparation or additional negotiation services after the files have been turned over to the attorney.) Total Fee for Appraisals,Appraisal Reviews,and Acquisitions: $30,900. Assumptions (1) City to provide preliminary title reports. (2) City or Engineering consultant to provide legal descriptions and exhibit maps. (3) City or Engineering consultant to provide construction plan sheets of the project. (4) City will close in-house or through a title company. (5) No relocation. Note Based on preliminary design information, two of the properties have potential impact problems due to the taking. Appraisal and negotiation issues could be problematic for these files. Consultant shall make every effort to acquire the right of way within budget. However,proposed budget is limited to what is considered to be reasonably normal appraisal/acquisition effort and will not be adequate for prolonged or complex negotiations. 11IPage EXHIBIT B CONSULTANTS PROPOSAL 12IPAge