Loading...
Mr. Electric ~ C110040 ■ April 20,2015 City of Tigard Mr. Electric Attn: Jim KTeiser 418 NE Repass Rd. P-6 Vancouver,WA 98665 REF.: City of Tigard Agreement Servicing of Electric Maintenance Period: March 15,2015 through March 16, 2016 CONTRACT NOTICE OF AWARD—RENEWAL Contract#C110040 Dear Mr. Kleiser: The City of'Tigard has determined that your company has performed in accordance vnth the requirements of our Agreement. Therefore, the City of Tigard, pursuant to the renewal/extension clause contained in the terms and conditions of the Agreement, desires to exercise its fourth (4th) one-}rear extension to the Contract effective from March 15, 2015 through March 16, 2016. This renewal period shall be governed by the specifications, pricing, and the terms and conditions set forth per the above referenced Contract. Please acknowledge acceptance of this renewal by signing this document in the space provided below and returning it to me within ten (10) days. You may keep a copy for your records. The City looks forward to doing business with Mr. Electric in the neat year. Sincerely, ,j�' ie Greenb Purchasing Assistant 503-718-2492 jamie@tigard-or.gov I f We hereby- acknowledge acceptance of this Contract renes 1, and agree to be bound by all requirements, terms, and conditions as set forth in the abov eferenced Contract. Compare �` `r 1 _ Signed: Date: Printed: 13125 SW Fall Blvd. - Tigard, Oregon 97223 5033.639.4171 TTY Relay: 503.684.2772 0 www.tigard-or.gov April 21, 2014 Mr. Electric Attn: Jim Kleiser 418 NE Repass Rd. B-6 Vancouver, WA 98665 REF.: City of Tigard Agreement Servicing of Electric Maintenance Period: March 15, 2014 through March 16, 2015 CONTRACT NOTICE OF AWARD - RENEWAL Mr. Electric Contract #C110040 Dear Mr. Kleiser: The City of Tigard has determined that your company has performed in accordance with the requirements of our Agreement. Therefore, the City of Tigard, pursuant to the renewal/extension clause contained in the terms and conditions of the Agreement, desires to exercise its third (3rd) one-year extension to the Contract effective from March 15, 2014 through March 16, 2015. This renewal period shall be governed by the specifications, pricing, and the terms and conditions set forth per the above referenced Contract. Please acknowledge acceptance of this renewal by signing this document in the space provided below and returning it to me within ten (10) days. You may keep a copy for your records. The City looks forward to doing business with Mr. Electric in the next year. Sincerely, 4 4,o,- Michelle Wright Business Manager 503-718-2445 MichelleW @tigard-or.gov I/We hereby acknowledge acceptance of this Contract renewa nd agree to be bound by all requirements, terms, and conditions as set forth in the above e enced Contract. Company: � - �� ��� Signed: Date: 2- "c Printed: �� ' r UaC�J''jc i r � March 1, 2013 City of Tigard Mr. Electric -[9 Attn: Jim Kleiser 14300 NE 20th Ave ,102-313 Vanc , A 98686 REF.: City of Tigard Agreement Servicing of Electric Maintenance Period: March 15, 2013 through March 16, 2014 CONTRACT NOTICE OF AWARD - RENEWAL Dear Mr. Kleiser: The City of Tigard has determined that your company has performed in accordance with the requirements of our Agreement. Therefore, the City of Tigard, pursuant to the renewal/extension clause contained in the terms and conditions of the Agreement, desires to exercise its second (2nd) one-year extension to the Contract effective from March 15, 2013 through March 16, 2014. This renewal period shall be governed by the specifications, pricing, and the terms and conditions set forth per the above referenced Contract. Please acknowledge acceptance of this renewal by signing this document in the space provided below and returning it to me 'within ten (10) days. You may keep a copy for your records. The City looks forward to doing business with Mr. Electric in the next year. I Sincerely, Michelle Wright Business Manager 503-718-2445 MichelleW@tigard-or.gov I/We hereby acknowledgc acceptance of this Contract renew 1, and agree to be bound by all requirements, terms, and conditions as set forth in the abcm referenced Contract. Company: _ Signed: - �x/v�- Date: 1 ' Printed:La- L R 13125 SW Hall Blvd. @ Tigard, Oregon 97223 e 503.639.4171 TTY Relay: 503.684.2772 ® www.tigard-or.gov f Contract# U 44 CITY OF TIGARD,OREGON AGREEMENT FOR SERVICES RELATED TO ELECTRIC MAINTENANCE THIS AGREEMENT made and entered into this 15 of March, 2011 by and between the City of Tigard, a municipal corporation of the State of Oregon, hereinafter called "City," and Mr. Electric, hereinafter called "Contractor,"collectively known as the"Parries." RECITALS WHEREAS, Contractor has submitted a bid or proposal to City to provide specific services;and WHEREAS, Contractor is in the business of providing specific services and is aware of the purposes for which City requires the services;and WHEREAS, City and Contractor wish to enter into a contract under which City shall purchase the services described in Contractor's bid or proposal; THEREFORE,The Parties agree as follows: 1. SERVICES TO BE PROVIDED Contractor agrees to provide services related to Electric Maintenance as detailed in Exhibit A—Scope of Services and by this reference made a part hereof. 2. EFFECTIVE DATE AND DURATION Contractor shall initiate services upon receipt of City's notice to proceed, together with an executed copy of this Agreement. This Agreement shall become effective upon the date of execution and shall expire,unless otherwise terminated or extended,on March 15,2012.The City shall also retain the rights to four (4) one-year extensions to the Contract. All services shall be completed prior to the expiration of this agreement. 3. COMPENSATION City agrees to pay Contractor an amount not exceeding four thousand and 00/100 dollars ($4,000) for performance of those services described herein, which payment shall be based upon the following applicable terms: A. Payment will be made in installments based on Contractor's invoice, subject to the approval by the City, and not more frequently than monthly. Payment shall be made only for work actually completed as of the date of invoice. B. Payment by City shall release City from any further obligation for payment to Contractor, for services performed or expenses incurred as of the date of the invoice. Payment shall not be considered acceptance or approval of any work or waiver of any defects therein. C. Contractor shall make payments promptly,as due, to all persons supplying labor or materials for the prosecution of this work. Standard Purchase Agreement—General Services Page 1 Revised—05/14/2007 Contract# D. Contractor shall not permit any lien or claim to be filed or prosecuted against the City on any account of any labor or material furnished. E. Contractor shall pay to the Department of Revenue all sums withheld from employees pursuant to ORS 316.167. F. If Contractor fails, neglects or refuses to make prompt payment of any claim for labor or services furnished to Contractor or a subcontractor by any person as such claim becomes due, City may pay such claim and charge the amount of the payment against funds due or to become due the Contractor. The payment of the claim in this manner shall not relieve Contractor or their surety from obligation with respect to any unpaid claims. G. Contractor shall pay employees at least time and a half pay for all overtime worked in excess of 40 hours in any one work week except for individuals under the contract who are excluded under ORS 653.010 to 653.261 or under 29 USC sections 201 to 209 from receiving overtime. H. Contractor shall promptly, as due, make payment to any person, co-partnership, association or corporation, furnishing medical, surgical, hospital care or other needed care and attention incident to sickness or injury to the employees of Contractor or all sums which Contractor agrees to pay for such services and all moneys and sums which Contractor collected or deducted from the wages of employees pursuant to any law, contract or agreement for the purpose of providing or paying for such service. I. The City certifies that sufficient funds are available and authorized for expenditure to finance costs of this contract. 5. ASSIGNMENT/DELEGATION Neither party shall assign or transfer any interest in or duty under this Agreement without the written consent of the other and any attempted assignment or transfer without the written consent of the other party shall be invalid. 6. SUBMITTING BILLS AND MAKING PAYMENTS All notices and bills shall be made in writing and may be given by personal delivery, mail or fax. Payments may be made by personal delivery,mail,purchasing card,or electronic transfer. The following addresses shall be used to transmit notices,bills,payments,and other information: o . Attn:Nicklas Nissen Attn:Shawn Heinige Address: 13125 SVG'Hall Blvd. Address: 14300 NE 206.Avenue,D102-313 Tigard,Oregon 97223 Vancouver,VIA 98686 Phone: (503)718-2605 Phone: (503)296-8555 Fax: (503)684-8840 Fax: (360)546-2158 Email Address: ngn@tigard-or.gov Email address: shawnhQmrelectriccc.com 7. TERMINATION The parties agree that any decision by either party to terminate this Agreement before 15 of March, 2012 shall be accompanied by thirty (30) days written notice to the other party prior to the date Standard Purchase Agreement—General Services Page 2 Re-6sed—05/14/2007 Contract# termination would take effect. There shall be no penalty for early termination. If City terminates the contract pursuant to this paragraph,it shall pay Contractor for services rendered prorated to the date of termination. 8. ACCESS TO RECORDS City shall have access to such books, documents, papers and records of Contractor as are directly pertinent to this Agreement for the purpose of making audit,examination,excerpts and transcripts. 9. FORCE MMEURE Neither City not Contractor shall be considered in default because of any delays in completion and responsibilities hereunder due to causes beyond the control and without fault or negligence on the part of the parties so disenabled,including but not restricted to, natural disaster, war, civil unrest, volcano, earthquake, fire, flood, epidemic, quarantine restriction, area-wide strike, freight embargo, unusually severe weather or delay of subcontractor or supplies due to such cause; provided that the parties so disenabled shall within ten (10) days from the beginning of such delay,notify the other party in writing of the cause of delay and its probable extent. Such notification shall not be the basis for a claim for additional compensation. Each party shall,however,make all reasonable efforts to remove or eliminate such a cause of delay or default and shall,upon cessation of the cause,diligently pursue performance of its obligation under the Agreement. 10. NON-DISCRIMINATION Contractor agrees to comply with all applicable requirements of federal and state civil rights and rehabilitation statues, rules, and regulations. Contractor also shall comply with the Americans with Disabilities Act of 1990, ORS 659.425,and all regulations and administrative rules established pursuant to those laws. 11. INDEMNITY/HOLD HARMLESS Contractor shall defend, indemnify and hold harmless City, City's officers, employees, agents and representatives from and against all liability, claims, demands, judgments, penalties, and causes of action of any kind or character, or other costs or expenses incidental to the investigation and defense thereof, of whatever nature, resulting from or arising out of the activities of the Contractor or its subcontractors, agents, or employees under this contract, except, however, that the foregoing shall not apply to liability that arises out of City's sole negligence. 12. INSURANCE Contractor shall maintain insurance acceptable to City in full force and effect throughout the term of this contract. Such insurance shall cover all risks arising directly or indirectly out of Contractor's activities or work hereunder. The policy or policies of insurance maintained by the Contractor shall provide at least the following limits and coverages: A. Commercial General Liability Insurance Contractor shall obtain, at contractor's expense, and keep in effect during the term of this contract, Comprehensive General Liability Insurance coveting Bodily Injury and Property Standard Purchase Agreement—General Services Page 3 Revised—05/14/2007 Contract# Damage on an "occurrence" form (1996 ISO or equivalent). This coverage shall include Contractual Liability insurance for the indemnity provided under this contract. The following insurance will be carried: Coverage Limit General Aggregate 2,000,000 Products-Completed Operations Aggregate 1,000,000 Personal&Advertising Injury 1,000,000 Each Occurrence 1,000,000 Fire Damage (any one fire) 50,000 Medical Expense (any one person) 5,000 B. Business Automobile Liability Insurance If Contractor will be delivering any goods or services which require the use of a vehicle, Contractor shall provide City a certificate indicating that Contractor has business automobile liability coverage for all owned,hired,and non-owned vehicles. The Combined Single Limit per occurrence shall not be less than $1,000,000. Said insurance shall name City as an additional insured and shall require written notice to City thirty (30) days in advance of cancellation. If Contractor hires a carrier to make delivery, Contractor shall ensure that said carrier complies with this paragraph. C. Workers' Compensation Insurance The Contractor and all employers providing work, labor or materials under this Contract that are either subject employers under the Oregon Workers' Compensation Law and shall comply with ORS 656.017,which requires them to provide workers' compensation coverage that satisfies Oregon law for all their subject workers or employers that are exempt under ORS 656.126. Out-of-state employers must provide Oregon workers' compensation coverage for their workers who work at a single location within Oregon for more than 30 days in a calendar year. Contractors who perform work without the assistance or labor of any employee need not obtain such coverage. This shall include Employer's Liability Insurance with coverage limits of not less than$500,000 each accident. D. Insurance Carrier Rating All coverage provided by the Contractor must be underwritten by an insurance company deemed acceptable by the City. The City reserves the right to reject all or any insurance carrier(s)with an unacceptable financial rating. E. Certificates of Insurance As evidence of the insurance coverage required by the contract, the Contractor shall furnish a Certificate of Insurance to the City. No contract shall be effected until the required certificates have been received and approved by the City. The procuring of such required insurance shall not be construed to limit contractor's liability hereunder. Notwithstanding said insurance, Contractor shall be obligated for the total amount of any damage, injury,or loss caused by negligence or neglect connected with this contract. Standard Purchase agreement—General Services Page 4 Revised—05/14/2007 Contract# 13. ATTORNEY'S FEES In case suit or action is instituted to enforce the provisions of this contract, the parties agree that the losing party shall pay such sum as the court may adjudge reasonable attorney fees and court costs, including witness fees (expert and non-expert),attorney's fees and court costs on appeal. 14. COMPLIANCE WITH STATE AND FEDERAL LAWS/RULES Contractor shall comply with all applicable federal, state and local laws, rules and regulations, including, but not limited to, the requirements concerning working hours, overtime, medical care, workers compensation insurance, health care payments, payments to employees and subcontractors and income tax withholding contained in ORS Chapter 279B, the provisions of which are hereby made a part of this agreement. 15. CONFLICT BETWEEN TERMS It is further expressly agreed by and between the parties hereto that should there be any conflict between the terms of this instrument in the proposal of the contract, this instrument shall control and nothing herein shall be considered as an acceptance of the terms of proposal conflicting herewith. 16. SEVERABILITY In the event any provision or portion of this Agreement is held to be unenforceable or invalid by any court of competent jurisdiction, the validity of the remaining terms and provisions shall not be affected to the extent that it did not materially affect the intent of the parties when they entered into the agreement. 17. INDUSTRIAL ACCIDENT FUND PAYMENT Contractor shall pay all contributions or amount due the Industrial Accident Fund form that Contractor or subcontractors incur during the performance of this Agreement. 18. COMPLETE AGREEMENT This Agreement, including the exhibits, is intended both as a final expression of the Agreement between the parties and as a complete and exclusive statement of the terms. In the event of an inconsistency between a provision in the main body of the Agreement and a provision in the Exhibit, the provision in the main body of the Agreement shall control. In the event of an inconsistency between Exhibit A and Exhibit B,Exhibit A shall control. No modification of this Agreement shall be effective unless and until it is made in writing and signed by both parties. No waiver, consent, modification, or change of terms of this Agreement shall bind either party unless in writing and signed by both parties. Such waiver, consent, modification, or change if made, shall be effective only in specific instances and for the specific purpose given. There are no understandings, agreements, or representations, oral or written, not specified herein regarding this Agreement. Contractor, by the signature of its authorized representative, hereby acknowledges that Contractor has read this Agreement,understands it and agrees to be bound by its terms and conditions. IN WITNESS WHEREOF, City has caused this Agreement to be executed by its duly authorized undersigned officer and Contractor has executed this Agreement on the date hereinabove first written. Approved by Tigard's Local Contract Review Board: Standard Purchase Agreement—General Services Page 5 Revised—05/14/2007 Contract# CITY dOGARD: MR. EL/C- /�RVI V By: Authorized City Representative By: Au zed ontractor Representative Date Date Standard Purchase Agreement—General Services Page 6 Revised—05/14/2007 Contract# EXHIBIT A SCOPE OF SERVICES ELECTRICAL 1VIAINTENANCE AT CITY FACILITIES The City of Tigard is seeking a firm or individual"Service Provider" to provide Electrical Maintenance at City facilities. Service Description The Service Provider will: 1. Furnish all supervision,labor,materials, transportation and equipment necessary to evaluate,monitor and provide electrical repair and maintenance services for City facilities. 2. Be licensed in the State of Oregon to perform the tasks required under this Scope of Work and will furnish the City with proof of current licensing. Furthermore, the Service Provider will comply with all federal and state electrical maintenance requirements and regulations. Services: Examples of Essential Functions: • Install new electrical services and equipment;run conduit for fixtures,receptacles, control circuits, and lighting; select and install wires,accomplish hookups and test installation. • Install new electrical wiring and connections for low voltage systems including voice, data, security devices and surveillance cameras. • Perform various technical work including diagnosing motors for overloading and failure;perform voltage and resistance tests;calibrate solid state circuit boards;upgrade existing electrical services. • Resolve problems of balancing electrical loads,peak loading, overloading and phasing. • Evaluate each job situation as it arises;diagnose electrical problems and search for proper solutions; refer problems to appropriate staff • Perform standard computations relating to dimensions of work;amount, type and size of electrical wire, fittings required; and weight, support and location. • Purchase electrical parts,materials and supplies as needed;maintain minimum inventories;perform record keeping duties for parts and materials used. • Estimate material and labor costs necessary for electrical installations,upgraded electrical services, and repair projects. Standard Purchase Agreement—General Services Page 7 Revised—05/14/2007 i Contract# EXHIBIT B CONTRACTOR'S PROPOSAL Mr. Electric will be providing the City of Tigard electrical maintenance: The special rates below were established for the City of Tigard. Category Straight Time Overtime Sundays/Holidays Foreman $88.00 $123.00 $163.00 ourne man $85.00 $115.00 $157.00 Apprentice 5th-10th $73.00 $102.00 $135.00 Apprentice 1st-4th $56.00 $78.00 $104.00 Fire,Life,&Safety $85.00 $115.00 $157.00 Lighting Maintenance $67.00 $94.00 $124.00 IR Imagining $88.00 $123.00 $163.00 • Special rates are good until March 15,2012. • Travel time is charged at normal rates;it is usually 1/z hour per call. Overtime and Sundays/holidays have a two-hour minimum. • Rentals,permits, subcontractors are charged at cost plus 10%. • Rates above include an electrician, service truck, small tools, and communication devices. Time of Completion: March 15,2012. Total cost: $4,000 annually Standard Purchase Agreement—General Services Page 8 Revised—05/14/2007