Murray, Smith and Associates, Inc (MSA) ~ C150037 City of Tigard
CONTRACT CHANGE ORDER 13125 SW Hall Blvd.
• ' AMENDMENT SUMMARY Tigard,Oregon 97223
Phone-(503) 639-4171
FIELD CHANGE ORDER FORM Fax-(503) 684-7297
www. d-or. ov
Project Title:Analysis of 550 connections to Price Res Project Manager: Aaron Beattie
Contractor: Murray, Smith and Associates (MSA) Original Contract#: 150037
Effective Dates: 11/24/14— 12/31/14 Chane Order/Amendment Amount: $
Accounting String:53 0-6500-54001 1 Amendment Percentage Running Total: %
AMENDMENT DETAILS
CHANGE ORDER DETAILS UNIT QTY UNIT$ TOTAL$
Extend effective date to 2/28/15
REASONING FOR CHANGE ORDER/AMENDMENT
More time need to complete the analysis of connections to Price reservoir than forecasted due to late start on
project.
REQUESTING PROJECT ' AGER APPROVING CITY STAFF
Signature Signature
Date Date
Contractor is hereby authorized by the City of Tigard to perform CONTRACTOR
the additional work described below in accordance with the terms
and conditions detailed in the original contract along with all
applicable rules, regulations, and laws that may be in effect for
the work. The unit pricing in the original contract shall apply to Signature
all additional work. A copy of this form, once completed, is to
be forwarded to the Purchasing Office to ensure all changes to
the encumbrances are met. Remember—the cumulative total
of Amendments cannot exceed the project's FY budget. Date
CITY OF TIGARD,OREGON
AMENDMENT TO CONTRACT
ANALYSIS OF PROPOSED 550 ZONE CONNECTIONS TO THE PRICE RESERVOIR
C150037
AMENDMENT #1
The Agreement between the City of Tigard, a municipal corporation of the State of Oregon, hereinafter
called City, and Murray, Smith and Associates, hereinafter referred to as Contractor, entered into on the 28`'
day of October, 2014,is hereby amended as follows:
2. Effective Date and Duration
This agreement shall become effective upon the date of execution and shall expire, unless otherwise
terminated or extended, upon completion of the work or Dee 4,2 February 28, 2015,
whichever comes first. All work under this Agreement shall be completed prior to the expiration of
this Agreement.
IN WITNESS WHEREOF, City has caused this Amendment to be executed by its duly authorized
undersigned officer and Contractor has executed this Amendment upon signature and date listed below.
CITY OF TIG MURRAY SMITH AND ASSOCIATES,INC
Signa—tpl_ Signature
Printed Name Printed Name
JK )
Date Date
CITY OF TIGARD,OREGON-CONTRACT SUMMARY FORM
THIS FORMMUST ACCOMPANYEVERY CONTRACT
Contract Title: 550 pressure zone connections to Price Reservoir_Number:�� I S c>c�
Contractor: Murray Smith and Associates,Inc. (MSA) Contract Total: $10,000.00
Contract Overview: MSA is performing engineering analysis to determine total amount of equivalent
residential dwelling units that can be offloaded from the 713 zone storage capacity by
connecting 550E.D,C pressure zones to the Price reservoir. This analysis will
included engineers estimate of probable design and construction cost.
Initial Risk Level: ❑ Extreme ❑ High ❑ Moderate ow
Risk Reduction Steps: Risk is minimal to perform engineering study.
Risk Comments:
Risk Signature:
Contract Manager:Aaron R Beattie Ext: 2690 Department: Public Works
Type: ❑ Purchase Agreement ❑ Personal Service ❑ General Service ❑ Public Improvement
❑ IGAOther:E I',5 f L�?e-e if i�S 5 r v✓i�s5 Start Date: 10/29/14 End Date: 12/31/14
0 5".e,--Im e,-�
Quotes/Bids/Proposal- FIRM AMOUNT/ CORE
Murray Smith Associates,Inc. Not to exceed$10,000.00
Account String. Fund-Division-Account Work Order-Activil<-Type Amount
Year 1 530-6500-54001 S 10,000.00
Year 2
Year 3
Year 4
Year 5
Approvals - LCRB Date:
Department Comments: QBS Direct Appointment
Department Signature:
Purchasing Comments:
Purchasing Signature:
City Manager Comments:
City Manager Signature:
Contract Numbec
CITY OF TIGARD,OREGON
ENGINEERING SERVICES AGREEMENT
ANALYSIS OF PROPOSED 550 ZONE CONNECTIONS TO THE PRICE RESERVOIR
THIS AGREEMENT, made and entered into this 28th day of October, 2014,by and between the
City of Tigard, a municipal corporation, hereinafter referred to as the "City," and Murray Smith &
Associates, Inc., whose authorized representative is Brian Ginter, and having a principal being a
registered engineer of the State of Oregon,hereinafter referred to as the "Engineer."
RECITALS
WHEREAS, the City's Fiscal Year 2014-2015 budget provides for engineering services for the
Analysis of the proposed 550-zone connections to the Price reservoir project; and
WHEREAS, the accomplishment of the work and services described in this Agreement is necessary
and essential to the public works improvement program of the City; and
WHEREAS, the City desires to engage the Engineer to render professional engineering services for
the project described in this Agreement, and the Engineer is willing and qualified to perform such
services;
THEREFORE, in consideration of the promises and covenants contained herein, the parties
hereby agree as follows:
1. Engineer's Scope of Services
The Engineer shall perform professional engineering services relevant to the Project in
accordance with the terms and conditions set forth herein, and as provided in Exhibit A,
which is attached hereto and by this reference made a part of this Agreement.
2. Effective Date and Duration
This agreement shall become effective upon the date of execution and shall expire, unless
otherwise terminated or extended,upon completion of the work or Dec 31, 2014,whichever
comes first. All work under this Agreement shall be completed prior to the expiration of
this Agreement.
3. Engineer's Fee
A. Basic Fee
1) As compensation for Basic Services as described in Exhibit A of this
Agreement, and for services required in the fulfillment of Paragraph 1, the
Engineer shall be paid on an hourly rate based upon the "Schedule of Rates"
in Exhibit B of this agreement, which shall constitute full and complete
payment for said services and all expenditures which may be made and
expenses incurred, except as otherwise expressly provided in this Agreement.
The Basic Fee shall not exceed the amount of ten thousand and no/100
Dollars ($10,000.00) without prior written authorization.
2) The parties hereto do expressly agree that the Basic Fee is based upon the
Scope of Services to be provided by the Engineer and is not necessarily
related to the estimated construction cost of the Project. In the event that
the actual construction cost differs from the estimated construction cost, the
Engineer's compensation will not be adjusted unless the Scope of Services to
be provided by the Engineer changes and is authorized and accepted by the
City.
B. Payment Schedule for Basic Fee
Payments shall be made upon receipt of billings based on the work completed.
Billings shall be submitted by the Engineer periodically,but not more frequently than
monthly. Payment by the City shall release the City from any further obligation for
payment to the engineer for service or services performed or expenses incurred as of
the date of the statement of services. Payment shall be made only for work actually
completed as of the date of invoice. Payment shall not be considered acceptance or
approval of any work or waiver of any defects therein.
C. Payment for Special Services
Only when directed in writing by the City, the Engineer shall furnish or acquire for
the City the professional and technical services based on the hourly rate schedule as
described in Exhibit A of this contract for minor project additions and/or
alterations.
A Certified Cost Records
The Engineer shall furnish certified cost records for all billings pertaining to other
than lump sum fees to substantiate all charges. For such purposes, the books of
account of the Engineer shall be subject to audit by the City. The Engineer shall
complete work and cost records for all billings on such forms and in such manner as
will be satisfactory to the City.
E. Contract Identification
The Engineer shall furnish to the City its employer identification number, as
designated by the Internal Revenue Service, or social security number, as the City
deems applicable.
F. Payment—General
1) Engineer shall pay to the Department of Revenue all sums withheld from
employees pursuant to ORS 316.167.
2) Engineer shall pay employees at least time and a half pay for all overtime
worked in excess of 40 hours in any one week except for individuals under
the contract who are excluded under ORS 653.010 to 653.261 or under 29
USC sections 201 to 209 from receiving overtime.
3) Engineer shall promptly, as due, make payment to any person, co-
partnership, association or corporation, furnishing medical, surgical and
hospital care or other needed care and attention incident to sickness or injury
to the employees of Engineer or all sums which Engineer agrees to pay for
such services and all moneys and sums which Engineer collected or deducted
21Page
ESA Template—Revised 11/19/2013
from the wages of employees pursuant to any law, contract or agreement for
the purpose of providing or paying for such service.
4) The City certifies that sufficient funds are available and authorized for
expenditure to finance costs of this contract.
5) Engineer shall make payments promptly, as due, to all persons supplying
services or materials for work covered under this contract. Engineer shall
not permit any lien or claim to be filed or prosecuted against the City on any
account of any service or materials furnished.
6) If Engineer fails, neglects or refuses to make prompt payment of any claim
for labor, materials, or services furnished. to Engineer, sub-consultant or
subcontractor by any person as such claim becomes due, City may pay such
claim and charge the amount of the payment against funds due or to become
due to the Engineer. The payment of the claim in this manner shall not
relieve Engineer or their surety from obligation with respect to any unpaid
claims.
4. Ownership of Plans and Documents: Records
A. The field notes, design notes, and original drawings of the construction plans, as
instruments of service, are and shall remain, the property of the Engineer; however,
the City shall be furnished, at no additional cost, one set of previously approved
reproducible drawings as well as storage device such as thumb drive or sd card in
"DWG" or "DXF" format, of the original drawings of the work. The City shall
have unlimited authority to use the materials received from the Engineer in any way
the City deems necessary.
B. The City shall make copies, for the use of and without cost to the Engineer, of all of
its maps, records, laboratory tests, or other data pertinent to the work to be
performed by the Engineer pursuant to this Agreement, and also snake available any
other maps, records, or other materials available to the City from any other public
agency or body.
C. The Engineer shall furnish to the City, copies of all maps, records, field notes, and
soil tests which were developed in the course of work for the City and for which
compensation has been received by the Engineer at no additional expense to the City
except as provided elsewhere in this Agreement.
5. Assignment/Delegation
Neither party shall assign, sublet or transfer any interest in or duty under this Agreement
without the written consent of the other and no assignment shall be of any force or effect
whatsoever unless and until the other party has so consented. If City agrees to assignment of
tasks to a subcontract, Engineer shall be fully responsible for the acts or omissions of any
subcontractors and of all persons employed by them, and neither the approval by City of any
subcontractor not anything contained herein shall be deemed to create any contractual relation
between the subcontractor and City.
31Page
ESA Template—Revised 11/19/2013
6. Engineer is Independent Contractor
A. The City's project director, or designee, shall be responsible for determining whether
Engineer's work product is satisfactory and consistent with this agreement, but
Engineer is not subject to the direction and control of the City. Engineer shall be an
independent contractor for all purposes and shall be entitled to no compensation
other than the compensation provided for under Section 3 of this Agreement.
B. Engineer is an independent contractor and not an employee of City. Engineer
acknowledges Engineer's status as an independent contractor and acknowledges that
Engineer is not an employee of the City for purposes of workers compensation law,
public employee benefits law, or any other law. All persons retained by Engineer to
provide services under this contract are employees of Engineer and not of City.
Engineer acknowledges that it is not entitled to benefits of any kind to which a City
employee is entitled and that it shall be solely responsible for workers compensation
coverage for its employees and all other payments and taxes required by law.
Furthermore, in the event that Engineer is found by a court of law or an
administrative agency to be an employee of the City for any purpose, City shall be
entitled to offset compensation due, or to demand repayment of any amounts paid
to Engineer under the terms of the agreement, to the full extent of any benefits or
other remuneration Engineer receives (from City or third party) as a result of said
finding and to the full extent of any payments that City is required to make (to
Engineer or to a third party) as a result of said finding.
C. The undersigned Engineer hereby represents that no employee of the City or any
partnership or corporation in which a City employee has an interest, has or will
receive any remuneration of any description from the Engineer, either directly or
indirectly,in connection with the letting or performance of this Agreement, except as
specifically declared in writing.
D. If this payment is to be charged against Federal funds, Engineer certifies that he/she
is not currently employed by the Federal Government and the amount charged does
not exceed his/her normal charge for the type of service provided.
E. Engineer and its employees, if any, are not active members of the Oregon Public
Employees Retirement System and are not employed for a total of 600 hours or
more in the calendar year by any public employer participating in the Retirement
System.
F. Engineer shall obtain, prior to the execution of any performance under this
Agreement, a City of Tigard Business License. The Tigard Business License is based
on a calendar year with a December 31st expiration date. New businesses operating
in Tigard after June 30th of the current year will pay a pro-rated fee though the end
of the calendar year.
G. Engineer is not an officer, employee, or agent of the City as those terms are used in
ORS 30.265.
4 1 P a g e
ESA Template—Revised 11/19/2013
7. Indemnity
A. The City has relied upon the professional ability and training of the Engineer as a
material inducement to enter into this Agreement. Engineer represents to the City that
the work under this contract will be performed in accordance with the professional
standards of skill and care ordinarily exercised by members of the engineering profession
under similar conditions and circumstances as well as the requirements of applicable
federal, state and local laws, it being understood that acceptance of an Engineer's work
by the City shall not operate as a waiver or release. Acceptance of documents by City
does not relieve Engineer of any responsibility for design deficiencies, errors or
omissions.
B. Claims for other than Professional Liability. Engineer agrees and shall indemnify,
defend, save and hold harmless the City of Tigard, its officers, employees, agents, and
representatives from all claims, suits, or actions and all expenses incidental to the
investigation and defense thereof, of whatsoever nature, including intentional acts
resulting from or arising out of the activities of Engineer or its subcontractors, sub-
consultants, agents or employees in performance of this contract at both trial and appeal
level, whether or not a trial or appeal ever takes place including any hearing before
federal or state administrative agencies.. If any aspect of this indemnity shall be found to
be illegal or invalid for any reason whatsoever, such illegality or invalidity shall not affect
the validity of the remainder of this indemnification.
C. Claims for Professional Liability. Engineer agrees and shall indemnify, defend, save and
hold harmless the City of Tigard, its officers, employees, agents, and representatives
from all claims, suits, or actions and all expenses incidental to the investigation and
defense thereof, arising out of the professional negligent acts, errors or omissions of
Engineer or its subcontractors, sub-consultants, agents or employees in performance of
professional services under this agreement. Any work by Engineer that results in a
design of a facility that is not readily accessible to and usable by individuals with
disabilities shall be considered a professionally negligent act, error or omission.
D. As used in subsections B and C of this section, a claim for professional responsibility is a
claim made against the City in which the City's alleged liability results directly or
indirectly, in whole or in part, from the quality of the professional services provided by
Engineer, regardless of the type of claim made against the City in performance of this
contract. A claim for other than professional responsibility is a claim made against the
City in which the City's alleged liability results from an act or omission by Engineer
unrelated to the quality of professional services provided by Engineer in performance of
this contract.
8. Insurance
Engineer and its subcontractors shall maintain insurance acceptable to City in full force and
effect throughout the tern of this contract. Such insurance shall cover risks arising directly or
indirectly out of Engineer's activities or work hereunder, including the operations of its
subcontractors of any tier. Such insurance shall include provisions that such insurance is
5 1 P a g e
ESA Template—Revised 11/19/2013
primary insurance with respect to the interests of City and that any other insurance maintained
by City is excess and not contributory insurance with the insurance required hereunder.
The policy or policies of insurance maintained by the Engineer and its subcontractors shall
provide at least the following limits and coverages:
A. Commercial General Liability Insurance
Engineer shall obtain, at Engineer's expense, and keep in effect during the term of this
contract, Comprehensive General Liability Insurance covering Bodily Injury and Property
Damage on an "occurrence" form (CG 2010 1185 or equivalent). This coverage shall
include Contractual Liability insurance for the indemnity provided under this contract. The
following insurance will be carried:
Coverage Limit
General Aggregate $3,000,000
Products-Completed Operations Aggregate $2,000,000
Personal&Advertising Injury $1,000,000
Each Occurrence $2,000,000
Fire Damage (Any one fire) $50,000
B. Professional Liability
Engineer shall obtain, at Engineer's expense, and keep in effect during the term of this
contract, Professional Liability Insurance covering any damages caused by any actual or
alleged negligent act, error or omission in the rendering of or failure to render Professional
Services. Combined single limit per claim shall not be less than $2,000,000, or the
equivalent. Annual aggregate limit shall not be less than$3,000,000 and filed on a "claims-
made" form.
C. Commercial Automobile Insurance
Engineer shall also obtain, at Engineer's expense, and keep in effect during the term of the
contract (Symbol 1 or Symbols 8 and 9 as applicable) Commercial Automobile Liability
coverage on an"occurrence" form including coverage for all owned, hired, and non-owned
vehicles. The Combined Single Limit per occurrence shall not be less than$2,000,000.
If Contractor operates a personally-owned vehicle for business use under,this contract, the
Contractor shall obtain, at Contractor's expense, and keep in effect during the term of the
contract, business automobile liability coverage for all owned vehicles on an "occurrence"
form. The Combined Single Limit per occurrence shall not be less than$2,000,000.
D. Workers' Compensation Insurance
The Engineer, its subcontractors, if any, and all employers providing work, labor or
materials under this Contract are subject employers under the Oregon Workers'
Compensation Law and shall comply with ORS 656.017, which requires them to provide
workers' compensation coverage that satisfies Oregon law for all their subject workers.
Out-of-state employers must provide Oregon workers' compensation coverage for their
workers who work at a single location within Oregon for more than 30 days in a calendar
year. Engineers who perform work without the assistance or labor of any employee need
61Page
ESA Template—Revised 11/19/2013
not obtain such coverage. This shall include Employer's Liability Insurance with coverage
limits of not less than$1,000,000 each accident.
E. Additional Insured Provision
All policies aforementioned, other than Workers' Compensation and Professional Liability,
shall include the City its officers, employees, agents and representatives as additional
insureds with respect to this contract. Coverage will be endorsed to provide a"per project"
aggregate.
F. Extended Reporting Coverage
If any of the aforementioned liability insurance is arranged on a "claims-made" basis,
Extended Reporting coverage will be required at the completion of this contract to a
duration of 24 months or the maximum time period the Engineer's insurer will provide
such if less than 24 months. Engineer will be responsible for furnishing certification of
Extended Reporting coverage as described or continuous "claims-made" liability coverage
for 24 months following contract completion. Continuous "claims-made" coverage will be
acceptable in lieu of Extended Reporting coverage, provided its retroactive date is on or
before the effective date of this contract. Coverage will be endorsed to provide a "per
project" aggregate.
G. Insurance Carrier Rating
Coverage provided by the Engineer must be underwritten by an insurance company
deemed acceptable by the City. All policies of insurance must be written by companies
having an A.M. Best rating of"A-VII" or better, or equivalent. The City reserves the right
to reject all or any insurance carrier(s)with an unacceptable financial rating.
H. Self-Insurance
The City understands that some Contractors may self-insure for business risks and the City
will consider whether such self-insurance is acceptable if it meets the minimum insurance
requirements for the type of coverage requited. If the Contractor is self-insured for
commercial general liability or automobile liability insurance the Contractor must provide
evidence of such self-insurance. The Contractor must provide a Certificate of Insurance
showing evidence of the coverage amounts on a form acceptable to the City. The City
reserves the right in its sole discretion to determine whether self-insurance is adequate.
I. Certificates of Insurance
As evidence of the insurance coverage required by the contract, the Engineer shall furlish a
Certificate of Insurance to the City. No contract shall be effective until the required
Certificates of Insurance have been received and approved by the City. The certificate will
specify and document all provisions within this contract and include a copy of Additional
Insured Endorsement. A renewal certificate will be sent to the address below prior to
coverage expiration.
J. Independent Contractor Status
The service or services to be rendered under this contract are those of an independent
contractor. Contractor is not an officer, employee or agent of the City as those terms are
used in ORS 30.265.
71Page
ESA Template—Revised 11/19/2013
K. Primary Coverage Clarification
The parties agree that Engineer's coverage shall be primary to the extent permitted by law.
The parties further agree that other insurance maintained by the City is excess and not
contributory insurance with the insurance required in this section.
L. Cross-Liability Clause
A cross-liability clause or separation of insureds clause will be included in all general liability
and commercial automobile policies required by this contract.
A certificate in form satisfactory to the City certifying to the issuance of such insurance will be
forwarded to:
City of Tigard
Attn: Contracts and Purchasing Office
13125 SW Hall Blvd
Tigard, Oregon 97223
At the discretion of the City, a copy of each insurance policy, certified as a true copy by an
authorized representative of the issuing insurance company may be required to be forwarded to
the above address.
Such policies or certificates must be delivered prior to commencement of the work.
The procuring of such required insurance shall not be construed to limit Engineer's liability
hereunder. Notwithstanding said insurance,Engineer shall be obligated for the total amount of
any damage,injury,or loss caused by negligence or neglect connected with this contract.
9. Termination Without Cause
I
At any time and without cause, City shall have the fight in its sole discretion, to terminate this
Agreement by giving notice to Engineer. If City terminates the contract pursuant to this
paragraph,it shall pay Engineer for services rendered to the date of termination.
10. Termination With Cause
A. City may terminate this Agreement effective upon delivery of written notice to
Engineer, or at such later date as may be established by City, under any of the
following conditions:
1) If City funding from federal, state,local, or other sources is not obtained and
continued at levels sufficient to allow for the purchase of the indicated
quantity of services. This Agreement may be modified to accommodate a
reduction in funds.
I
2) If Federal or State regulations or guidelines are modified, changed, or
interpreted in such a way that the services are no longer allowable or
appropriate for purchase under this Agreement.
8 1 P a g e
ESA Template—Revised 11/19/2013
3) If any license or certificate required by law or regulation to be held by
Engineer, its subcontractors, agents, and employees to provide the services
required by this Agreement is for any reason denied, revoked, or not
renewed.
4) If Engineer becomes insolvent, if voluntary or involuntary petition in
bankruptcy is filed by or against Engineer,if a receiver or trustee is appointed
for Engineer, or if there is an assignment for the benefit of creditors of
Engineer.
Any such termination of this agreement under paragraph (A) shall be without
prejudice to any obligations or liabilities of either party already accrued prior to such
termination.
B. City, by written notice of default (including breach of contract) to Engineer, may
terminate the whole or any part of this Agreement:
1) If Engineer fails to provide services called for by this agreement within the
time specified herein or any extension thereof, or j
2) If Engineer fails to perform any of the other provisions of this Agreement,
or so fails to pursue the work as to endanger performance of this agreement
in accordance with its terms, and after receipt of written notice from City,
fails to correct such failures within ten days or such other period as City may
authorize.
3) If Engineer fails to eliminate a conflict as described in Section 14 of this
agreement.
The rights and remedies of City provided in the above clause related to defaults
(including breach of contract) by Engineer shall not be exclusive and are in addition to
any other rights and remedies provided by law or under this Agreement. If City
terminates this Agreement under paragraph (B), Engineer shall be entitled to receive
as full payment for all services satisfactorily rendered and expenses incurred, an
amount which bears the same ratio to the total fees specified in this Agreement as
the services satisfactorily rendered by Engineer bear to the total services otherwise
required to be performed for such total fee; provided, that there shall be deducted
from such amount the amount of damages,if any, sustained by City due to breach of
contract by Engineer. Damages for breach of contract shall be those allowed by
Oregon law, reasonable and necessary attorney fees, and other costs of litigation at
trial and upon appeal.
11. Non-Waiver
The failure of City to insist upon or enforce strict performance by Engineer of any of the
terms of this Agreement or to exercise any rights hereunder, should not be construed as a
waiver or relinquishment to any extent of its rights to assert or rely upon such terms or rights
on any future occasion.
9 1 P a g e
ESA Template—Revised 11/19/2013
12. Method and Place of Giving Notice, Submitting Bills and Making Payments
All notices, bills and payments shall be made in writing and may be given by personal delivery,
mail, or by fax. Payments may be made by personal delivery, mail, or electronic transfer. The
following addresses shall be used to transmit notices,bills,payments,and other information:
CITY OF TIGARD MURRAY SMITH&ASSOCIATES,INC.
Attn: Aaron Beattie Attn: Brian Ginter j
Address: 13125 SW Hall Blvd. Address: 121 SW Salmon, Suite 900
Tigard, Oregon 97223 Portland, Oregon 97204
Phone: (503) 718-2690 Phone: (503)225-9010
Fax: (503) 684-8840 Fax: (503)225-9022
Email: abeattie@tigard-or.gov Email: Brian.Ginter@rasa-ep.com
and when so addressed, shall be deemed given upon deposit in the United States mail, postage
prepaid, or when so faxed, shall be deemed given upon successful fax. In all other instances,
notices,bills and payments shall be deemed given at the time of actual delivery. Changes may
be made in the names and addresses of the person to whom notices, bills and payments are to
be given by giving written notice pursuant to this paragraph.
13. Merger
This writing is intended both as a final expression of the Agreement between the parties with
respect to the included terms and as a complete and exclusive statement of the terms of the
Agreement. No modification of this Agreement shall be effective unless and until it is made in
writing and signed by both parties.
14. Professional Services
The City requires that services provided pursuant to this agreement shall be provided to the
City by an Engineer, which does not represent clients on matters contrary to City interests.
Further, Engineer shall not engage services of an engineer and/or other professional who
individually, or through members of his/her same firm, represents clients on matters contrary
to City interests.
Should the Engineer represent clients on matters contrary to City interests or engage the
services of an engineer and/or other professional who individually, or through members of
his/her same firm, represents clients on matters contrary to City interests, Engineer shall
consult with the appropriate City representative regarding the conflict.
After such consultation, the Engineer shall have seven (7) days to eliminate the conflict to the
satisfaction of the City. If such conflict is not eliminated within the specified time period, the
agreement may be terminated pursuant to Section 10 (B -3) of this agreement.
15. Force Majeure
Neither City nor Engineer shall be considered in default because of any delays in completion
and responsibilities hereunder due to causes beyond the control and without fault or
negligence on the part of the parties so disenabled, including but not restricted to, an act of
God or of a public enemy, civil unrest, volcano, earthquake, fire, flood, epidemic, quarantine
101Page
ESA Template—Revised 11/19/2013
restriction, area-wide strike, freight embargo, unusually severe weather or delay of
subcontractor or supplies due to such cause; provided that the parties so disenabled shall
within ten days from the beginning of such delay, notify the other party in writing of the cause
of delay and its probable extent. Such notification shall not be the basis for a claim for
additional compensation. Each party shall, however, make all reasonable efforts to remove or
eliminate such a cause of delay or default and shall, upon cessation of the cause, diligently
pursue performance of its obligation under the Agreement.
16. Non-Discrimination
Engineer agrees to comply with all applicable requirements of federal and state civil rights and
rehabilitation statues, rules, and regulations. Engineer also shall comply with the Americans
with Disabilities Act of 1990, ORS 659A.142, and all regulations and administrative rules
established pursuant to those laws.
17. Errors
Engineer shall perform such additional work as may be necessary to correct errors in the work
required under this Agreement without undue delays and without additional cost.
18. Extra (Changes) Work
Only the City's Project Manager may authorize extra (and/or change) work. Failure of
Engineer to secure authorization for extra work shall constitute a waiver of all right to.
adjustment in the contract price or contract time due to such unauthorized extra work and
Engineer thereafter shall be entitled to no compensation whatsoever for the performance of
such work.
19. Governing Law
The provisions of this Agreement shall be construed in accordance with the provisions of the
laws of the State of Oregon. Any action or suits involving any question arising under this
Agreement must be brought in the appropriate court of the State of Oregon.
20. Compliance With Applicable Law
Engineer shall comply with all federal, state, and local laws and ordinances applicable to the
work under this Agreement,including those set forth in ORS 279A,279B,and 279C.
21. Conflict Between Terms
It is further expressly agreed by and between the parties hereto that should there be any
conflict between the terms of this instrument in the proposal of the contract, this instrument
shall control and nothing herein shall be considered as an acceptance of the said terms of said
pro posal conflicting herewith.
22. Access to Records
City shall have access to such books, documents, papers and records of Engineer as are
directly pertinent to this Agreement for the purpose of making audit, examination, excerpts
and transcripts.
11Page
ESA Template—Revised 11/19/2013
23. Audit
Engineer shall maintain records to assure conformance with the terns and conditions of this
Agreement, and to assure adequate performance and accurate expenditures within the contract
period. Engineer agrees to permit City, the State of Oregon, the federal government, or their
duly authorized representatives to audit all records pertaining to this Agreement to assure the
accurate expenditure of funds.
24. Severability
In the event any provision or portion of this Agreement is held to be unenforceable or invalid
by any court of competent jurisdiction, the validity of the remaining terms and provisions shall
not be affected to the extent that it did not materially affect the intent of the parties when they
entered into the agreement.
25. Complete Agreement
This Agreement,including the exhibits,is intended both as a final expression of the Agreement
between the Parties and as a complete and exclusive statement of the terms. In the event of an
inconsistency between a provision in the main body of the Agreement and a provision in the
Exhibits, the provision in the main body of the Agreement shall control. In the event of an
inconsistency between Exhibit A and Exhibit B,Exhibit A shall control.
No waiver, consent,modification, or change of terms of this Agreement shall bind either party
unless in writing and signed by both parties. Such waiver, consent, modification, or change if
made, shall be effective only in specific instances and for the specific purpose given. There are
no understandings, agreements, or representations, oral or written, not specified herein
regarding this Agreement. Engineer, by the signature of its authorized representative, hereby
acknowledges that he/she has read this Agreement, understands it and agrees to be bound by
its terms and conditions.
IN WITNESS WHEREOF, City has caused this Agreement to be executed by its duly authorized
undersigned officer and Engineer has executed this Agreement on the date hereinabove first written.
Awarded by Tigard's Local Contract Review Boaril at their meeting.
CITY OF TIGARD MURRAY SMITH&ASSOCIATES,INC.
By: Breager,PublicVArks Director By:Authorized Contractor Representative
Date Date
121Page
ESA Template—Revised 11/19/2013
EXHIBIT A
SCOPE OF SERVICES for
The City of Tigard
ENGINEERING ANALYSIS OF PROPOSED 550 ZONE CONNECTIONS TO THE PRICE RESERVOIR
Background
The City of Tigard 713-service level is deficient in water storage for existing conditions based on the
criteria used in the 2010 Water System Master Plan and unable to provide expanded capacity for the
River Terrace area. The Master Plan did not recommend additional storage at the time due to ample
pumping capacity to meet demands. The building of a 550-service level reservoir on the Cache
property and accompanying pump station would address this current deficiency and provide
expanded capacity for River Terrace. Budgetary and staffing constraints create feasibility concerns
for the completion of this project in the short term. Offloading existing 550-service level areas D,
C, and E from the 713-service level to the surplus storage capacity of the 550-service level Price
reservoir would free up additional capacity. If viable this would reduce the deficiency in the upper
service levels, and provide available storage capacity for initial development in the River Terrace
area.
Staff is proposing the following routing of water line and connections: Continue existing 550-zone
waterline from Price reservoir north on 125th Ave to connect to existing 550E-zone piping.
Continue new waterline northwest on Gaarde to Greenfield and connect to 12" 550D-zone piping.
Continue new water line or repurpose existing piping from the discharge and inlet of the abandoned
132nd pump station to make connection to the 550C-zone.
Scope of Services
Task 1
Perform an engineering study to determine the hydraulic feasibility of connecting the 550 E,
D and C service levels and calculate number of equivalent residential dwelling units that can
be served by the 550-service level Price reservoir and be available to offset current
deficiencies in the 713-service level.
Task 2
Determine estimated piping sizes, route, and other improvements needed to connect the
proposed 550-service levels to the Price reservoir.
Task 3
Prepare a preliminary engineering report or technical memorandum with the findings and
determination of the proposed project's hydraulic feasibility and an engineering estimate of
probable design, and construction costs. Include equivalent residential dwelling units
offloaded to the 550-service level Price reservoir and equivalent residential dwelling units
provided to available storage capacity in the 713 service-level.
131Page
ESA Template—Revised 11/19/2013
EXHIBIT B
ENGINEER'S PROPOSAL
I
14Page
ESA Template—Revised 11/19/2013
M- -SA
2014 SCHEDULE OF CHARGES
Personnel:
Labor will be invoiced by staff classification at the following hourly rates,which are valid from January
1, 2014 to December 31,2014. After this period,the rates are subject to adjustment.
Principal Engineer V1 $210.00
Principal Engineer V 202.00
Principal Engineer IV 194.00
Principal Engineer III 186.00
Principal Engineer 11 180.00
Principal Engineer I 172.00
Professional Engineer IX 164.00
Professional Engineer VIII 156.00
Professional Engineer VII 148.00
Professional Engineer VI 140.00
Professional Engineer V 132.00
Professional Engineer IV 125.00
Engineering Designer IV 125.00
Professional Engineer III 117.00
Engineering Designer III 117.00
Engineering Designer II 108.00
Engineering Designer I 99.00
Technician IV 120.00
Technician 111 107.00
Technician II 93.00
Technician 1 79.00
Administrative 111 85.40
Administrative H 79.00
Administrative I 69.00
Project Expenses:
Expenses incurred in-house that are directly attributable to the project will be invoiced at actual cost.
These expenses include the following:
Computer Aided Design and Drafting $16.00/hour
Mileage Current IRS Rate
Communications Charge I%of Invoiced Labor
Postage and Delivery Services At Cost
Printing and Reproduction At Cost
Travel,Lodging and Subsistence At Cost
Outside Services:
Outside technical,professional and other services will be invoiced at actual cost plus
10 percent to cover administration and overhead.
Portland MURRAY,SMITH&ASSOCIATES,INC.
2014 Engineers/Planners